Question

In: Civil Engineering

Fact Situation: You are the Senior Project Manager for Wackinsmack, Inc., the general contractor on the...

Fact Situation:

You are the Senior Project Manager for Wackinsmack, Inc., the general contractor on the prime contract for the construction of a new waste water treatment plant for Dimwit County DPW. The Contract Price has grown to $115 million after Dimwit made adjustments to the scope of the Work and issued the appropriate Change Orders. Wackinsmack’s contract with Dimwit is based on the ConsensusDOCs, CD 200, “Owner/Prime Contractor” Form.

You have successfully negotiated the subcontract with Acme Mechanical, Inc. for $41 million, for the mechanical work, which does not include dewatering, and which provides for Wackinsmack to give lifting services for Acme at no cost. Acme has executed the subcontract, ConsensusDOCs, CD 750, “Prime/Subcontractor Subcontract.” In general, Acme’s subcontract consists of Wackinsmack’s standard subcontract form (ConsensusDOC CD 750) and is “complete, per plans and specifications” for the mechanical work on the Project, except for the exclusions you’ve negotiated, as identified above.

Over the course of construction, a number of events occur, which have caused Wackinsmack and its subcontractors extra cost and time to complete the work affected by the events.

In addition to the undisputed contract adjustments, Dimwit County has issued a number of additional Change Orders, which have provided for specific cost and time adjustments for certain items of changed work, and upon which Wackinsmack has “signed off.”   Where appropriate, Wackinsmack has “passed down” Change Orders to its subcontractors affected by the changes. As issued, the Dimwit Change Orders all contain language to the effect that the Change Order represents a complete and final resolution of all costs and time affects associated with the change, including direct and indirect costs.

Dimwit has refused to issue Change Orders for other work, claimed to be “extra” by Wackinsmack. Included in the pile of refused change orders, are two “Field Directives” issued by Dimwit’s Engineer (Ithinkican Engineering Consultants, Inc.) which the Owner feels are not changes to the Contract’s scope; a claim for Differing Site Conditions (DSC), which Dimit says Wackinsmack should have known about when bidding; and, the discovery of hazardous “contamination” in the excess excavated soil materials which has to be trucked off the site and disposed of in a Class II landfill (which Dimwit feels is Wackinsmack’s contractual responsibility).

The accumulation of changes, including those for which Dimwit has not agreed, has resulted in delays to the project. Wackinsmack failed to achieve Substantial Completion of the work by the Contract End Date (as adjusted by approved change orders). As a result Dimwit has assessed liquidated damages against Wackinsmack for late completion. Wackinsmack has, in turn, assessed Acme for 35.6% of the liquidated damages, based on Acme’s proportionate share of the prime contract price (ie. $41 million/$115 million).

One of the disputed Work Orders involves the direction by Ithinkican, to relocate a significant portion of the process piping (work performed by Acme) to avoid conflicts with other elements of the mechanical systems. Ithinkican has advised Dimwit that this work was part of the contractor’s “methods and means” responsibility and is not an extra. Ithinkican feels that since Acme has BIM capability it was up to Acme to identify conflicts (ie. clashes) in the piping system. Acme made the changes, and performed the work, and now claims $350,000 in extra costs and delay (which is yet to be determined because of the myriad of other changes, some approved, and others not approved).

The DSC conditions involved conflicts with existing underground utility lines (the County’s sanitary and storm sewer lines, and the main power feeds to the site, provided by Detroit Edison). The utility lines were not shown in their actual locations on the contract drawings and as a result, conflicted with excavation on the site. In some instances, the utilities had to be relocated to avoid the conflicts. In the case of the Edison lines, which are buried, they weren’t shown at all on the contract documents. Ithinkican and Dimwit defend against the claim by arguing that Wackinsmack failed in its duty to visit and inspect the site prior to the bidding, and if there were irregularities in the drawings then Wackinsmack should have notified the Engineer and Owner in writing of the problems, prior to submitting bids. Because Wackinsmack failed to do those things, its claims have been waived.

As to the hazardous materials contaminating the site soils (the contamination was not disclosed by the contract documents) Ithinkican and Dimwit defend on the basis that ownership of excess materials on the site “is the contractor’s” and that the contractor is obligated to remove and dispose of the excess material in a legal manner. Accordingly, Dimwit has refused to issue a change order for the disposal of the contaminated soils because the Contract requires Wackinsmack to remove and dispose of it. Thus, Wackinsmack should have made provisions to dispose of the hazardous materials at a Class II landfill as part of its bid. It is noted that the contamination was caused by Dimwit’s disposal, on site, of contaminated ash from the incinerator before construction started . The incinerated ash looks like fine grained brown sand and was intermixed with the existing “clean” soils on site.

You may assume that Wackinsmack conducted a pre-bid inspection of the site; attended the mandatory pre-bid meeting; and, submitted written notices of the differing site conditions and hazardous materials. No formal written notice was submitted regarding the pipe conflicts, however, because of the significant changes that had to be made, Acme, Wackinsmack, Ithinkican and the Owner’s representatives had a number of meetings to discuss the conflicts and work out plans to avoid them. Subsequently, shop drawings were submitted, showing the adjustments, and approved by Ithinkican.

QUESTIONS

  1.          As to the Work Order issued by Ithinkican to relocate some of the process piping, (15                  Points)
  1.         Does the Work Order constitute an Interim Directed Change (Contract Change                              Directive) under the terms of the Contract? If so, why? (3 Points)

                       

  1.         Under the terms of the Contract, what are the pricing mechanisms for paying for                           changed work in the absence of a price agreement? (3 Points)

           

  1.         If Wackinsmack feels that the Work Order involves the performance of extra                                 work ,what obligation does Wackinsmack have to provide notice? (3 Points)

                       

  1.         In accordance with Wackinsmack’s contract with Dimwit, if notice is required,                              how is it to be given and to who is it to be given? (3 Points)
  1.          Under the circumstances of this situation, is Wackinsmack required to provide                               notice? Why or Why Not? (3 Points)

Solutions

Expert Solution

ANSWER A =    You have successfully negotiated the subcontract with Acme Mechanical, Inc. for $41 million, for the mechanical work, which does not include dewatering, and which provides for Wackinsmack to give lifting services for Acme at no cost. Acme has executed the subcontract, ConsensusDOCs, CD 750, “Prime/Subcontractor Subcontract.” In general, Acme’s subcontract consists of Wackinsmack’s standard subcontract form (ConsensusDOC CD 750) and is “complete, per plans and specifications” for the mechanical work on the Project, except for the exclusions you’ve negotiated,

and bacause they have different concract them such type mechanical contract Over the course of construction, a number of events occur, which have caused Wackinsmack and its subcontractors extra cost and time to complete the work affected by the events.  

ANSWER B = Price mechanism refers to the system where the forces of demand and supply determine the prices of commodities and the changes therein. It is the buyers and sellers who actually determine the price of a commodity. And to solve them the different type of contract are to be their to their complete the work. To limit misunderstandings and make them more legally binding, contracts are usually written documents that describe the obligations of both parties and are signed by those with authority to represent the interests of the parties.

ANSWER C =  Dimwit has refused to issue Change Orders for other work, claimed to be “extra” by Wackinsmack. Included in the pile of refused change orders, are two “Field Directives” issued by Dimwit’s Engineer (Ithinkican Engineering Consultants, Inc.) which the Owner feels are not changes to the Contract’s scope; a claim for Differing Site Conditions (DSC), which Dimit says Wackinsmack should have known about when bidding; and, the discovery of hazardous “contamination” in the excess excavated soil materials which has to be trucked off the site and disposed of in a Class II landfill. For causing very deases and very insect are to be their

ANSWER D =  The accumulation of changes, including those for which Dimwit has not agreed, has resulted in delays to the project for  As a result Dimwit has assessed liquidated damages against Wackinsmack for late completion. Wackinsmack has, in turn, assessed Acme for 35.6% of the liquidated damages, based on Acme’s proportionate share of the prime contract price  

ANSWER E = Because the reasons not given in two week notice


Related Solutions

You are the Construction Manager for the Design and Build Contractor (and PSCS) for a project...
You are the Construction Manager for the Design and Build Contractor (and PSCS) for a project involving the construction of a multi-screen cinema and retail complex. You have had safety concerns in relation to the appointed scaffolding company, over a three weeks period. The issues raising concern include scaffolds being handed over in an unsafe state (missing toe boards, inadequate bracing and ties), scaffold workers operating at height not being tied-off, poor housekeeping and storage of materials on-site. Outline your...
You are field manager for the general contractor on a multi-story office building under construction. The...
You are field manager for the general contractor on a multi-story office building under construction. The project has risen all 15 floors above the foundation. The roof is on and the exterior façade of the structure, consisting of alternating blue glass ribbon windows and red granite panels, has “dried in” the project many weeks ago. On the third, seventh and fifteenth floors, the executive offices located on the corners of the building have blue glass doors that lead outside to...
A construction project is carried out by a general contractor with the following descriptions: Project Duration:...
A construction project is carried out by a general contractor with the following descriptions: Project Duration: 3 months (Start: May 1st; End: July 31st) Contract Amount: 20,713+30,081+50,630+40,978+60,886+70,089+30,500+100,165+152,181 Budget Amount: 100,936+200,081+300,685 Contract Terms and Conditions Materials: The construction company pays material suppliers in full when it receives payment from the owner. On the last day of each month the construction company may bill the owner for the work completed during the month. The owner pays the monthly bills one month after...
You are the senior manager or audit engagement partner on Care For Kids Inc., a not-for-...
You are the senior manager or audit engagement partner on Care For Kids Inc., a not-for- profit organization that has a December 31 year-end. While performing year-end substantive procedures, the engagement team identified an error in the entity’s year-end adjusting entries. Care For Kids Inc. had inadvertently not recorded an unrealized gain of $5 million in one of its many investment portfolios. The investments total approximately $200 million. Through inquiry of client management, the engagement team learned that the accounting...
Congratulations! You have just been hired as a senior IT portfolio and project manager at a...
Congratulations! You have just been hired as a senior IT portfolio and project manager at a traditional large finance company. The company is looking to invest in new financial products and services. You are now in charge of all new strategic IT projects to enable and support these new products and services. In your team, you have many subject matter experts, analysts, product and project managers, either directly or indirectly working for you . (a) Describe all areas of the...
In a CM at Risk (CM/GC) project, is there privity of contract between the general contractor...
In a CM at Risk (CM/GC) project, is there privity of contract between the general contractor and the architect? Explain. On a construction project, who ultimately pays for bonds and insurance?
PROBLEM 5 If the general contractor of a project fails to pay its subcontractors, the subcontractors...
PROBLEM 5 If the general contractor of a project fails to pay its subcontractors, the subcontractors may file a lien against the owner’s property, and the project owner is required to pay the subcontractors. To avoid the lien against the property and payment to the subcontractors, what measures could the owner do?
Introduction While you are an analyst at Investment Counselors, Inc., the senior portfolio manager at your...
Introduction While you are an analyst at Investment Counselors, Inc., the senior portfolio manager at your firm makes a decision to increase sporting goods apparel manufacturer stocks in the firm's managed funds. You are assigned to recommend one stock as an initial investment to meet this long-run objective. You diligently analyze and evaluate all communication stocks and narrow the decision to two athletic shoe manufacturing companies: Nike and Reebok. The senior portfolio manager requests that you analyze the internal sources...
If the general contractor on a project decided to further pursue his/her claims to dispute methods...
If the general contractor on a project decided to further pursue his/her claims to dispute methods beyond adjudication, what are the possible options? List the advantages and disadvantages of each one of such options. In regards to construction contracts.
how can u partner in a 2 storey construction project as a general contractor? describe the...
how can u partner in a 2 storey construction project as a general contractor? describe the extent to which any other person or group maybe partnering on project. what are challenges and benefits to any partnering that is occuring? what is preventing any further partnering?
ADVERTISEMENT
ADVERTISEMENT
ADVERTISEMENT